Wstecz
Orzecznictwo

Z orzecznictwa Sądu Najwyższego: minimalna treść klauzuli kary umownej

W dniu 20 maja 2021 r. Sąd Najwyższy rozpoznając sprawę o sygn. akt IV CSKP 58/21 (publ. SIP Lex nr 3208506) wydał wyrok w którym określił minimalną treść klauzuli umownej kreującej obowiązek zapłaty kary umownej.

            Kara umowna jest to zastrzeżenie umowne kreujące obowiązek naprawienia szkody wynikłej z niewykonania lub nienależytego wykonania zobowiązania niepieniężnego przez zapłatę określonej kwoty pieniężnej.  W przedmiotowej sprawie strony zawarły umowę o roboty budowlane zastrzegając w jej treści karę umowną w wysokości 0,2% wartości przedmiotu umowy z podatkiem VAT za każdy dzień zwłoki z tytułu nieterminowego usunięcia wad stwierdzonych przy odbiorze oraz w okresie gwarancji i rękojmi. W skardze kasacyjnej skarżący podniósł, że tak ukształtowane postanowienie umowne nie spełnia wymogów art. 483 § 1 k.c., nie została w nim bowiem definitywnie określona suma stanowiąca karę umowną.

            W orzeczeniu Sąd Najwyższy wskazał, że minimalną treść klauzuli kary umownej określa art. 483 § 1 k.c., natomiast granice kształtowania tej treści wyznacza 3531 k.c. Do koniecznych elementów ważnej klauzuli umownej kreującej obowiązek zapłaty kary umownej zaliczyć należy określenie zobowiązania (albo pojedynczego obowiązku), którego niewykonanie lub nienależyte wykonanie rodzi obowiązek zapłaty kary oraz określenie sumy pieniężnej mającej stanowić naprawienie szkody wynikającej z niewykonania lub nienależytego wykonania zobowiązania (art. 483 § 1 k.c.). Strony umowy korzystają ze swobody w oznaczeniu sumy stanowiącej karę umowną (3531 k.c.), ich ustalenia muszą być jednak na tyle precyzyjne, aby umożliwiały obiektywne jej oznaczenie, a naruszenie tej zasady będzie skutkować sankcją nieważności tego zastrzeżenia umownego (art. 58 § 3 k.c.). Strony nie mogą zatem przyjąć konstrukcji prawnej zakładającej ustalenie w przyszłości podstawy naliczania kary umownej. Nie spełnia wymogu oznaczoności kary określenie jej przez odwołanie się nie do stałego lecz ocennego miernika wartości. Sąd Najwyższy podkreślił ponadto, że kara umowna za zwłokę, która ma w założeniu pełnić przede wszystkim funkcję stymulującą dłużnika do wykonania zobowiązania, może być ustalona według stawki odniesionej do określonego interwału czasowego (dzień, tydzień), która może zostać określona, jako ułamek (procent) wartości przedmiotu umowy.

 

            Nadto Sąd Najwyższy zwrócił uwagę na fakt, że funkcję limitującą możliwość naliczania kary umownej dodatkowo pełni przedawnienie. Roszczenie o karę umowną za zwłokę w terminowym usunięciu wady przedmiotu umowy o roboty budowlane, naliczaną za każdy dzień zwłoki, staje się wymagalne w pierwszym dniu po upływie terminu do usunięcia wady (art. 120 § 1 w zw. z art. 471 k.c.) Kara taka nie może być zatem skutecznie naliczana po upływie terminu przedawnienia na wykonanie przez dłużnika zobowiązania polegającego na usunięciu wad stwierdzonych w wykonanych robotach budowlanych w okresie rękojmi i gwarancji, skoro może on podjąć obronę przez podniesienie zarzutu przedawnienia (art. 117 § 2 k.c.).

 

#prawoumów #prawo budowlane #Adviser1989

 

Sprawdź pozostałe nasze wpisy

Wstecz
Prawo sportowe 09.05.2024
[Sports law] A few words explaining what sports law is and who a sports lawyer is and what he really does.

In this post, we present answers to a few questions related to sports law, also known as "lex sportiva," which often arise in our sports law practice conducted within ADVISER Armknecht & Partners attorneys-at-law Sports Law Firm. These questions were asked to the managing partner of our law firm, Bartosz Armknecht, who as a leading sports lawyer in our firm specializes in sports law. Bartosz Armknecht represents athletes in legal disputes and negotiations with sports clubs, both football players and female footballers, as well as athletes from other sports such as volleyball, basketball, combat sports including MMA, and athletes practicing table tennis or handball. Bartosz's legal experience in sports law is not limited to representing athletes in negotiations or in cases before sports arbitration courts. He also handles matters for football clubs, basketball clubs, or sailing clubs. These matters include sponsorship agreements, advertising agreements, player contracts, agreements with sports agents, including football agents, as well as ownership changes in sports clubs. His experience extends beyond traditional legal services and sports law advice. He also has experience in sports marketing, creating branding strategies in sports during crisis situations, as well as restructuring sports clubs or designing the structure of sports clubs (corporate governance). Sports Lawyer A sports lawyer is a specialized professional who deals with the legal aspects of sports activities. His tasks include negotiating contracts, representing athletes in legal disputes, advising on labor law, copyright law, and image rights. A sports lawyer must know the specifics of individual sports disciplines in order to effectively represent the interests of his clients. Encouragement to use the services of a sports lawyer For the Footballer "Are you a football player who wants to make the most of your opportunities both on and off the pitch? A sports lawyer will help you negotiate contracts, protect image rights and in matters related to transfers. Thanks to professional legal support, you will be able to focus on the game, and We will take care of your interests." For a Basketball Player "Your basketball career may bring many challenges, both on and off the court. Our sports lawyer will provide you with comprehensive legal services, including contract negotiations, management of image rights and protection against unfair practices. Focus on scoring points and we will take care of for your rights." For the Volleyball Player "As a volleyball player, you are exposed to a variety of legal challenges, from contracts with clubs to sponsorship issues. A sports lawyer will help you in negotiations, protecting your interests at every stage of your career. Thanks to our legal assistance, you will be able to fully enjoy your game, being sure that your legal affairs are in good hands." For the Handball Player "Handball is a dynamic and exciting sport that requires full commitment. Our sports lawyer supports handball players in contract negotiations, protection of image rights and in legal disputes. Trust us and you will be able to focus on scoring goals while we take care of Your legal matters." For the Boxer "Boxing is a sport full of challenges, both inside and outside the ring. Our sports lawyer will help you manage contracts, negotiate with promoters and protect your rights. With us, you will be able to focus on training and fights, being sure that your interests are legally protected." For the MMA Fighter "The career of an MMA fighter involves numerous legal challenges, from contracts with organizations to image issues. A sports lawyer will provide you with professional support in negotiations, protection of image rights and legal disputes. Focus on your career in the octagon, and we will take care of the rest " www.adviser.law Professional legal support is crucial for every athlete, regardless of the discipline. A sports lawyer with experience and knowledge in sports law will protect your interests, allowing you to fully focus on your sports career. Contact us to find out how we can help you!

Czytaj dalej
Prawo podatkowe
Prawo do obniżenia podatku VAT uzależnione od warunków po stronie dłużnika – Wyrok Trybunału Sprawiedliwości UE z dnia 15 października 2020 r – C-335/19

Artykuł 90 dyrektywy 2006/112 w sprawie wspólnego systemu podatku od wartości dodanej należy interpretować w ten sposób, że stoi on na przeszkodzie przepisom krajowym, które uzależniają obniżenie podstawy opodatkowania podatkiem od wartości dodanej (VAT) od warunku, by w dniu dostawy towaru lub świadczenia usług, a także w dniu poprzedzającym dzień złożenia korekty deklaracji podatkowej mającej na celu skorzystanie z tego obniżenia dłużnik był zarejestrowany jako podatnik VAT i nie był w trakcie postępowania upadłościowego lub w trakcie likwidacji, zaś wierzyciel był w dniu poprzedzającym dzień złożenia korekty deklaracji podatkowej nadal zarejestrowany jako podatnik VAT.

Czytaj dalej